42.1305 Contract clauses.

My Favorites


42.1305 Contract clauses.

42.1305 Contract clauses.

  1. (a) The contracting officer shall insert the clause at 52.242-14, Suspension of Work, in solicitations and contracts when a fixed-price construction or architect-engineer contract is contemplated.

  2. (b)

    1. (1) The contracting officer may, when contracting by negotiation, insert the clause at 52.242-15, Stop-Work Order, in solicitations and contracts for supplies, services, or research and development.

    2. (2) If a cost-reimbursement contract is contemplated, the contracting officer shall use the clause with its AlternateI.

  3. (c) The contracting officer shall insert the clause at 52.242-17, Government Delay of Work, in solicitations and contracts when a fixed-price contract is contemplated for supplies other than commercial or modified-commercial items. The clause use is optional when a fixed-price contract is contemplated for services, or for supplies that are commercial or modified-commercial items.